Construction Contractor for Main Building Completion (Австралия - Тендер #70510708)

Construction Contractor for Main Building Completion

Contact Details

Tim Wise

Email Address:
tenders@awm.gov.au

Web Address:
http://www.tenders.gov.au

ATM Documents Lodgement Page ATM ID: AWM001533 Agency: Australian War Memorial Category: 72100000 - Building construction and support and maintenance and repair services Close Date & Time: 10-Feb-2026 2:00 pm (ACT Local Time)
Show close time for other time zones Publish Date: 13-Jan-2026 Location: ACT
Canberra ATM Type: Expression of Interest Multi Agency Access: No Panel Arrangement: No Multi-stage: Yes Multi-stage Criteria: This REOI is the first stage of a two-stage procurement process. The objective of the REOI process is to shortlist Respondents that have demonstrated their capacity, capability and experience to provide the services required as per documentation provided. The next stage of the procurement process will be conducted as a Limited Tender - No Public View process. Selected shortlisted Respondents will be formally invited to participate in the next stage of the procurement process and provided with instructions on how to access the Tender documentation stored in AusTender. Description:

The Memorial is seeking a contractor to deliver the final building works for the Project. The aim of this procurement is to select a Construction Contractor to deliver the work to complete the Main Building (Contract).

The work is described in Schedule 1 - Project and Scope Brief and is primarily at the northern end of the Main Building and includes staff facilities and the preparation for fit-out of areas that are being converted from back of house to galleries. The work includes four distinct scope areas:

(a) Scope Area 1 - Hall of Valour;

(b) Scope Area 2 - Central Gallery;

(c) Scope Area 3 - Education and Staff Areas; and

(d) Scope Area 4 - Humanitarian Galleries 1 and 2.

Other Instructions:

Industry briefing and Site Walk

The Memorial will hold an industry briefing for Respondents to clarify the Memorial’s objectives and priorities for this REOI and to respond to questions arising out of this REOI process. The Industry Briefing will be undertaken via MSTeams videoconference.

Respondents must pre-register their attendance at the industry briefing with the Contact Officer no later than 5:00pm (Canberra, ACT, local time) on 19 January 2026. Attendance at the industry briefing will be at the Respondent’s own cost. Attendance at the industry briefing is strongly recommended to ensure that Respondents have a sound understanding of the project conditions and procurement approach. The industry briefing details are as follows:

Date: 20 January 2026

Location: MS Teams

Time: 2pm

Respondents are to advise by 5pm, 19 January 2026 of the email addresses of the participants. On the morning of 20 January 2026, the Memorial will send invites to all nominated emails. There is no limit on the number of representatives per Respondent.

The Memorial may change the date, location and/or time of the industry briefing at its absolute discretion, by issuing an addendum in accordance with clause 1.5 (Addenda and notices).

Respondents must not rely on a statement made at the industry briefing as amending or adding to this REOI unless that amendment or addition is confirmed by the Memorial in accordance with clause 1.4 (Addenda and notices).

Conditions for Participation:

There are no Conditions for Participation for this procurement.

Timeframe for Delivery:

The Works are expected to commence in May 2026 and be completed by end December 2026 (TBC).

Address for Lodgement: http://www.tenders.gov.au Addenda Available: View Addenda

Contact Details

Tim Wise

Email Address: tenders@awm.gov.au

Web Address: http://www.tenders.gov.au

ATM Documents Lodgement Page

Источник закупки

Перейти

Импорт - Экспорт по стране Австралия