Kincardine Bridge Southern Piled Viaduct Replacement (Ангилья - Тендер #38408197)

• Contract award notice

Results of the procurement procedure

Directive 2014/24/EU - Public Sector Directive

Directive 2014/24/EU

Section I: Contracting entity I.1) Name and addresses

Transport Scotland South East

Buchanan House, 58 Port Dundas Road

Glasgow

G4 0DX

UK

Contact person: Billy Minto

Telephone: +44 7824334325

E-mail: billy.minto@transport.gov.scot

NUTS: UKM82

Internet address(es)

Main address: https://www.transport.gov.scot/

Address of the buyer profile: https://www.publiccontractsscotland.gov.uk/search/Search_AuthProfile.aspx?ID=AA13185

I.2) Joint procurement

The contract is awarded by a central purchasing body

I.4) Type of the contracting authority

National or federal agency/office

I.5) Main activity

Other: Transport

Section II: Object II.1) Scope of the procurement II.1.1) Title

Kincardine Bridge Southern Piled Viaduct Replacement

Reference number: TS/ROADS/WKS/2021/03

II.1.2) Main CPV code

45221100

II.1.3) Type of contract

Works

II.1.4) Short description

Transport Scotland has identified the requirement to appoint a suitably experienced Main Contractor to undertake the replacement of the southern piled viaduct on the A985 Kincardine Bridge.

The works require the demolition of the existing Southern Piled Viaduct of the A985 Kincardine Bridge and replacement with a new five span structure.

This will require the design, provision and maintenance of a two directional temporary structure prior to the Southern Piled Viaduct being demolished. The new Southern Piled Viaduct is an Employer"s Design.

II.1.6) Information about lots

This contract is divided into lots: No

II.1.7) Total value of the procurement

Value excluding VAT: 16 847 774.50 GBP

II.2) Description II.2.2) Additional CPV code(s)

45221111

45221100

45262310

45221110

II.2.3) Place of performance

NUTS code:

UKM76

Main site or place of performance:

Kincardine Bridge Southern Piled Viaduct

(Easting 292562, Northing 687165)

II.2.4) Description of the procurement

Transport Scotland is an agency of the Scottish Government and contracts in the name of and on behalf of the Scottish Ministers. Transport

Scotland wishes to appoint a Main Contractor to undertake the replacement of the southern piled viaduct on the A985 Kincardine Bridge.

These works are due to commence in Winter 2022, for a period of approximately 24 months.

The Main Contractor will be procured through a competitive tender procedure, in accordance with the restricted procedure as stated in the

Public Contracts (Scotland) Regulations 2015. Due to project complexity, the project requires to be performed by a single contractor and as

such shall not be divided into lots.

To be considered for this contract economic operators are required to complete the Single Procurement Document (SPD) in accordance

with this Contract Notice. Economic operators shall be evaluated in accordance with the Public Contracts (Scotland) Regulations 2015, on

the basis of information they have provided within the SPD.

It is the intention that the project will operate a mandatory Project Bank Account (PBA), a project specific account ring fenced with

effective Trust status, for payment of the Contractor and his supply chain. The account shall be opened by the Scottish Ministers with The

Royal Bank of Scotland under the Banking Services Framework defined at

http://www.gov.scot/Topics/Government/Procurement/directory/pscontractcentgovt/BankingServices

It is intended that the PBA shall satisfy the minimum requirements for an effectively constituted Trust under Scots law. The use of a PBA by a Contractor shall be a contractual requirement. Any sub-contractors for which it is agreed shall not be paid through the PBA shall be

entitled to payment according to the prompt payment provisions provided within the Contract.

Project Details

This Contract Notice relates to the replacement of the southern piled viaduct of the Kincardine Bridge.

The provisional scope of the proposed works will include, but is not limited to:

- Fence and gated access to the worksite to prevent public access into the worksite;

- Design, design check, provision, operation and maintenance of any temporary works that may be required to carry out the works;

- Demolition of the existing southern piled viaduct and its existing steel propping system;

- Construction of a replacement southern piled viaduct in accordance with the Employer"s design;

- Construction of a temporary bridge, with pedestrian footpath, to the west of the southern piled viaduct, to allow continuous two-way traffic and pedestrian access 24 hours a day, 7 days a week;

- Waterproofing and re-surfacing of the replacement southern piled viaduct;

- Provision of Light and Heavy Recovery vehicles for the duration of the works to serve the carriageway with live traffic management;

- Development and implementation of a Communications Strategy, working with Traffic Scotland, BEAR Scotland (Transport Scotland’s Term Operating Company for the South East Scotland Trunk Road Unit), emergency services, stakeholders and liaison with the local community to minimise any delays, disruption and inconvenience caused, including implementation of environmental mitigation and monitoring measures;

- The appointed Contractor shall be required to ensure that the design, construction and completion of the works take account of all measures necessary to protect the environment in accordance with the contract.

- All other works generally associated with demolition and construction adjacent to a live trunk road carriageway;

- Provision of As-built drawings

- Contribution and assistance in developing a scheme specific Health and Safety File.

- Traffic Management - Refer to the Tender documents.

II.2.5) Award criteria

Quality criterion: Execution of works; comprehension of risks associated with works; management methodology; programming of the works; and Community Benefits / Weighting: 40

Cost criterion: Final tenders will be assessed against evaluation criteria to determine the most economically advantageous submission. / Weighting: 60

II.2.11) Information about options

Options: No

II.2.13) Information about European Union funds

The procurement is related to a project and/or programme financed by European Union funds: No

II.2.14) Additional information

Economic operators may be excluded from this competition if they are in any of the situations referred to in regulation 58 of the Public

Contracts (Scotland) Regulations 2015. Please refer to the full II.2.14 clause which can be downloaded via the Additional Documents,

located within the Additional Notice Options of the Public Contracts Scotland portal (www.publiccontractsscotland.gov.uk).

Section IV: Procedure IV.1) Description IV.1.1) Type of procedure

Restricted procedure

IV.1.3) Information about a framework agreement or a dynamic purchasing system

A dynamic purchasing system was set up

IV.1.8) Information about Government Procurement Agreement (GPA)

The procurement is covered by the Government Procurement Agreement: Yes

IV.2) Administrative information IV.2.1) Previous publication concerning this procedure

Notice number in the OJ S:

2022/S 000-000496

Section V: Award of contract

Contract No: TS/ROADS/WKS/2021/03

A contract/lot is awarded: Yes

V.2 Award of contract V.2.1) Date of conclusion of the contract

07/02/2023

V.2.2) Information about tenders

Number of tenders received: 2

Number of tenders received from SMEs: 0

Number of tenders received from tenderers from EU Member States: 0

Number of tenders received from tenderers from non-EU Member States: 2

Number of tenders received by electronic means: 2

The contract has been awarded to a group of economic operators: No

V.2.3) Name and address of the contractor

Balfour Beatty

5 Churchill Place, Canary Wharf

London

E14 5HU

UK

Telephone: +44 1698647587

NUTS: UKM84

Internet address(es)

URL: https://www.balfourbeatty.com

The contractor is an SME: No

V.2.4) Information on value of the contract/lot (excluding VAT)

Initial estimated total value of the contract/lot:

Total value of the contract/lot: : 16 847 774.50 GBP

V.2.5) Information about subcontracting Section VI: Complementary information VI.3) Additional information

Transport Scotland will conduct the proposed procurement process for the Contract on behalf of the Scottish Ministers. In the event of the

conclusion of the contract, the Contract will be entered into between the Scottish Ministers and the successful tenderer. The Contract terms

and conditions will be based on ICE Conditions of Contract 5th Edition, with bespoke amendments. The Scottish Ministers shall not evaluate any submission received past the specified deadline, unless the delay is caused by a situation out

with the control of the economic operator, the determination of which shall be at the sole discretion of the Scottish Ministers.

Economic operators which alter their composition after making a submission will be the subject of re-evaluation.

Any request by economic operators for clarification of any part of the documentation, which relate to the SPD submission, shall be made

through the Public Contracts Scotland portal. The deadline to submit clarifications is 1200hrs BST on 07/02/22.

Neither Transport Scotland nor the Scottish Ministers shall be responsible in any way to Economic Operators as a result of any delay or

failure in answering any request for clarification or any decision not to answer a request for clarification (either in full or in part). Absence

of a response from Transport Scotland or the Scottish Ministers shall not entitle Economic Operators to qualify their submission.

The Scottish Ministers reserve the right not to conclude any contract as a result of the procurement process initiated by this notice and to

make whatever changes the Scottish Minsters deem appropriate to the content, process, timing and structure of the procurement process.

Transport Scotland and the Scottish Ministers shall have no liability for any costs howsoever incurred by those participating in the

competition.

Economic operators should be aware that all information submitted to the Scottish Ministers may need to be disclosed and / or published by

the Scottish Ministers in compliance with the Freedom of Information (Scotland) Act 2002.

The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at

https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.

(SC Ref:722047)

VI.4) Procedures for review VI.4.1) Review body

Sheriff Clerk"s Office

PO Box 23, 1 Carlton Place

Glasgow

G5 9DA

UK

VI.4.3) Review procedure

Precise information on deadline(s) for review procedures:

An economic operator that suffers, or risks suffering, loss or damage attributable to a breach of duty under the Public Contracts (Scotland)

Regulations 2015 may bring proceedings in the Sheriff Court or the Court of Session.

VI.5) Date of dispatch of this notice

08/02/2023

Information added to the notice since publication.

Additional information added to the notice since it"s publication. Commodity Categories Commodity Categories
Delivery Locations Delivery Locations
Alert Region Restrictions

The buyer has restricted the alert for this notice to suppliers based in the following regions.

Alert Region Restrictions

Источник закупки

Перейти

Импорт - Экспорт по стране Ангилья